Terms of Service

Agreement to Terms

By accessing or using the services provided by Tinney's Marketing ("we," "us," or "our"), you agree to be bound by these Terms of Service ("Terms"). If you do not agree to these Terms, please do not use our services.

These Terms apply to all visitors, users, and others who access or use our website tinneys.co or engage our marketing services.

Services Provided

Tinney's Marketing provides custom website design and development, SEO optimization, Google Ads management, and related digital marketing services. Specific services, deliverables, timelines, and pricing are detailed in individual service agreements or proposals.

Service Agreements

Upon engaging our services, you will enter into a separate service agreement that outlines:

• Scope of work and deliverables
• Project timeline and milestones
• Pricing and payment terms
• Revision and approval processes
• Responsibilities of both parties

Payment Terms

Deposits and Payment Schedule

• A 40% deposit is typically required to begin work
• Remaining payments are due according to the agreed schedule
• Final payment is due upon project completion or before launch

Late Payments

• Suspension of work until payment is received
• Delayed project timelines
• Late fees as specified in your service agreement

Refunds

Deposits are generally non-refundable once work has commenced. Refund eligibility for other payments depends on the stage of the project and will be addressed on a case-by-case basis.

Intellectual Property

Client-Owned Materials

You retain ownership of all materials, content, and intellectual property you provide to us, including logos, brand assets, written content, and images.

Work Product

Upon full payment, you own the final deliverables created specifically for your project.

Our Rights

• Display completed work in our portfolio
• Use project details as case studies (with your permission)
• Reuse general techniques, methods, and code libraries
• Attribute credit for the work we've created

Client Responsibilities

• Provide timely feedback and approvals
• Supply necessary materials, content, and access credentials
• Respond to communications within reasonable timeframes
• Make timely payments according to the agreed schedule
• Ensure you have rights to all materials you provide

Warranties and Disclaimers

We warrant that:

• Services will be performed with reasonable care and skill
• Deliverables will substantially conform to specifications
• We have the right to provide the services

However, we do not warrant that:

• Your website will be error-free or uninterrupted
• Specific results or rankings will be achieved
• Services will meet all of your requirements
• Third-party services will function as expected

Limitation of Liability

• Our total liability shall not exceed the amount paid for the specific service in question
• We are not liable for indirect, incidental, special, or consequential damages
• We are not responsible for third-party services, hosting, or platform issues

Termination

By Client

You may terminate services by providing written notice. Deposits are non-refundable and you are responsible for payment of all work completed to date.

By Us

We may terminate services if payment is not received as agreed, you breach these Terms, or continuing the relationship is not feasible.

Governing Law

These Terms are governed by the laws of the State of Missouri, United States. Any disputes shall be resolved in the courts of Jackson County, Missouri.

Contact Us

If you have any questions about these Terms of Service, please contact us: